Terms and Conditions
FIG Construction Services LLC
Effective Date: October 20, 2026
Website: https://figconstructionservices.com
Phone: (407) 205-8901
Florida Certified General Contractor: CGC1540893
1. Introduction and Acceptance of Terms
Welcome to FIG Construction Services LLC (“FIG Construction Services,” “FIG,” “we,” “our,” or “us”).
These Terms and Conditions govern your access to and use of our website, online forms, consultation scheduling services, and related digital communications.
FIG Construction Services provides residential and commercial construction, design-build services, construction management, remodeling, renovations, home accessibility modifications, and related construction solutions throughout our designated Florida service areas.
By accessing or using our website, you agree to these Terms and Conditions and our Privacy Policy. If you do not agree, please discontinue use of the website.
Construction services are governed by separately executed written agreements. These website terms do not replace or modify any signed construction contract.
We may update these terms periodically. Updated terms become effective when published on our website, unless otherwise specified. Changes will not retroactively modify existing signed project agreements.
2. Website Use
Our website is intended to provide information about FIG Construction Services, describe our capabilities, and allow prospective customers to request information, schedule consultations, and submit project inquiries.
Users agree not to:
Use our website for unlawful or fraudulent activities.
Attempt unauthorized access to our website, systems, or customer information.
Disrupt website functionality or compromise its security.
Upload or transmit malicious software or harmful content.
Misrepresent their identity or submit knowingly inaccurate information.
Copy, reproduce, or commercially exploit website materials without authorization.
We reserve the right to restrict access when necessary to protect our website, customers, or business operations.
3. Construction Services
FIG Construction Services provides construction-related services that may include:
New residential construction and custom home building.
Commercial construction and tenant improvements.
Design-build construction and project coordination.
Residential remodeling and renovations.
Construction management and preconstruction services.
Home accessibility and mobility modifications.
Wheelchair ramps, accessible bathrooms, walk-in showers, grab bars, and safer entryways.
Interior modifications, structural improvements, and other construction-related services.
Service availability depends on project location, scope, permitting requirements, scheduling, and applicable licensing.
Submission of an inquiry does not guarantee project acceptance, scheduling availability, or a contractual commitment.
4. Consultations, Estimates, and Proposals
Information provided through our website, telephone consultations, or preliminary project discussions is intended for general planning purposes.
Initial pricing discussions and preliminary estimates may be based on limited information and should not be interpreted as guaranteed construction prices.
Final project pricing may depend on:
Verified measurements and existing site conditions.
Approved construction drawings and specifications.
Material selections and product availability.
Labor and subcontractor pricing.
Permit requirements and applicable building codes.
Structural conditions and concealed damage.
Client-requested modifications.
Unforeseen conditions identified during construction.
Written proposals remain valid for the period stated in the proposal. When no validity period is specified, FIG may require pricing reconfirmation before contract execution.
A proposal does not constitute an accepted construction contract unless expressly agreed to in a binding written agreement.
FIG reserves the right to decline project opportunities that do not meet its operational, financial, safety, licensing, or scheduling requirements.
5. Construction Contracts and Project Agreements
All construction projects must be governed by a written agreement identifying the applicable project requirements.
Depending on the project, the agreement may establish:
Scope of work and exclusions.
Contract price and payment schedule.
Project duration and milestones.
Owner and contractor responsibilities.
Material selections and specifications.
Permitting and inspection obligations.
Change-order procedures.
Insurance requirements.
Warranty provisions.
Project completion and closeout requirements.
Dispute resolution procedures.
If these website Terms and Conditions conflict with an executed project agreement, the executed project agreement controls the project-specific obligations.
6. Customer Responsibilities
Customers engaging FIG Construction Services agree to cooperate reasonably in facilitating the successful execution of their projects.
Responsibilities may include:
Providing accurate property and project information.
Disclosing known property defects and hazardous conditions.
Providing reasonable access to the work area.
Obtaining required owner, landlord, or homeowner association approvals.
Making selections and approving documents within agreed timeframes.
Maintaining appropriate property insurance.
Making payments in accordance with the signed agreement.
Communicating changes through authorized project representatives.
Keeping unauthorized persons, children, and pets away from active construction areas.
Responsibility for obtaining permits and arranging inspections will be established in the project agreement and must comply with applicable law.
Delays resulting from unavailable access, incomplete information, or delayed owner decisions may affect project scheduling and costs as provided in the contract.
7. Payment Terms
Payment requirements are established in the applicable signed project agreement and must comply with Florida law.
Depending on the project, payment arrangements may include:
Initial deposits or mobilization payments.
Progress payments based on established milestones.
Payments for approved change orders.
Final payment in accordance with contractual completion requirements.
Payments may be accepted through approved methods, including checks, electronic bank transfers, and credit cards.
Any applicable payment processing charges will be disclosed before payment and assessed only where legally permitted.
Late payments, suspension of work, collection costs, and other remedies will be governed by the executed agreement and applicable law.
FIG Construction Services reserves all lawful rights and remedies for unpaid construction services, including applicable construction lien rights under Florida law.
8. Change Orders and Additional Work
Any modification to the agreed construction scope should be documented through an authorized written change order before the additional work begins.
Change orders may address:
Revised scope of work.
Additional or reduced construction costs.
Material substitutions.
Adjustments to construction schedules.
Additional labor or subcontractor requirements.
Changes resulting from concealed or unforeseen conditions.
Additional work is not automatically included in the original contract price.
Authorization, pricing, and payment for additional work will be determined under the executed agreement and applicable law.
9. Project Scheduling and Delays
FIG Construction Services makes reasonable efforts to establish realistic project schedules and maintain consistent progress.
Construction schedules may be affected by circumstances including:
Severe weather and unsafe working conditions.
Permit and inspection processing.
Material shortages and delivery delays.
Unforeseen structural or site conditions.
Owner-directed changes.
Delayed payments or owner decisions.
Utility interruptions.
Events beyond the reasonable control of the parties.
Project commencement dates, substantial completion requirements, extensions of time, and any contractual remedies for delay will be governed by the signed project agreement.
10. Workmanship and Product Warranties
FIG Construction Services is committed to performing construction work in a professional and workmanlike manner consistent with applicable contract requirements, building codes, and industry standards.
Specific workmanship warranty coverage, duration, exclusions, and claim procedures will be identified in the applicable construction agreement.
Warranty coverage may exclude, to the extent permitted by law:
Normal wear and tear.
Improper maintenance or misuse.
Damage caused by third parties.
Unauthorized alterations or repairs.
Damage resulting from accidents or external events.
Preexisting conditions outside the contracted scope.
Product failures not attributable to FIG’s installation or workmanship.
Manufacturer warranties may apply separately to installed products and materials.
Nothing in these terms limits warranties, rights, or remedies that cannot lawfully be waived under applicable Florida law.
11. Home Accessibility and Mobility Modification Services
FIG Construction Services provides construction-based accessibility improvements intended to make residential spaces safer, more functional, and easier to navigate.
Services may include accessible bathroom renovations, wheelchair ramps, grab bars, entryway modifications, walk-in showers, doorway improvements, and related construction work.
These services are construction services and do not constitute medical treatment, occupational therapy, rehabilitation, or a guarantee against accidents, injuries, or falls.
Where a project requires a clinical evaluation, medical recommendation, or specialized accessibility assessment, the customer may need to consult an appropriately licensed professional.
Construction work will be performed according to the agreed scope, applicable codes, and project requirements.
12. Permits, Inspections, and Code Compliance
Construction activities requiring permits or inspections will be handled in accordance with applicable Florida laws, local building department requirements, and the executed project agreement.
FIG Construction Services will coordinate contractor-responsible inspections as established in the contract.
Customers acknowledge that permit reviews, municipal approvals, and inspection schedules may affect project timelines.
No representation on our website should be interpreted as a guarantee that a proposed improvement will receive regulatory approval.
13. Construction Site Safety
Active construction areas may contain hazardous conditions, equipment, materials, exposed surfaces, and restricted access zones.
FIG Construction Services maintains responsibility for its applicable construction safety obligations.
Customers and visitors must comply with reasonable site access restrictions and safety instructions.
Customers should notify FIG of known property hazards, including suspected asbestos, lead-based paint, concealed utilities, structural instability, or other potentially dangerous conditions.
Nothing in these terms releases FIG Construction Services from liability that cannot lawfully be excluded.
14. Website Forms and Customer Communications
Our website may provide forms for:
General inquiries.
Construction consultation requests.
Project information submissions.
Home accessibility service requests.
Appointment scheduling.
Customer follow-up communications.
By submitting information, you authorize FIG Construction Services to contact you regarding your inquiry or requested services using the contact information provided.
Communications may occur through telephone, email, or other methods you have authorized.
Marketing text messages and automated promotional communications are subject to separate, applicable consent requirements. Submitting a website inquiry does not automatically constitute consent to receive promotional text messages or automated marketing calls.
Where marketing messages are offered, applicable consent disclosures and opt-out instructions will be provided.
Our collection, use, and protection of personal information are further described in our Privacy Policy.
15. Appointment Scheduling and Cancellations
Customers may request consultations or appointments through our website or designated scheduling systems.
Appointment requests are subject to confirmation and availability.
FIG Construction Services may reschedule appointments due to operational requirements, emergencies, weather conditions, or other reasonable circumstances.
Any consultation fees, cancellation charges, or rescheduling policies will be disclosed before they apply.
16. Intellectual Property
The FIG Construction Services name, logo, website content, photographs, graphics, written materials, and other original materials are owned by FIG Construction Services or used with appropriate authorization.
These materials may not be reproduced, distributed, modified, or used for commercial purposes without prior written permission, except as permitted by law.
17. Third-Party Websites and Services
Our website may contain links to third-party platforms, including scheduling services, payment processors, social media platforms, and other service providers.
FIG Construction Services does not control the independent policies or operations of third-party websites.
Use of these platforms may be subject to their respective terms and privacy policies.
18. Website Information and Disclaimer
FIG Construction Services makes reasonable efforts to maintain accurate and current website information.
However, website content is provided for general informational purposes and may change without notice.
Project photographs, descriptions, service examples, and general construction information do not guarantee identical results for every property or project.
Individual results depend on existing conditions, approved scope, materials, construction methods, and applicable regulations.
Nothing on the website constitutes architectural, engineering, legal, medical, or financial advice.
19. Limitation of Liability
To the maximum extent permitted by applicable law, FIG Construction Services will not be liable for indirect, incidental, special, or consequential damages arising solely from use of its website.
Nothing in these website terms limits liability for fraud, willful misconduct, personal injury, property damage, statutory violations, or other liability that cannot lawfully be excluded.
Liability associated with construction services will be governed by the applicable signed project agreement and controlling law.
20. Dispute Resolution
If a dispute arises concerning use of the website, the parties are encouraged to attempt resolution through good-faith communication.
If an informal resolution cannot be reached, either party may pursue available legal remedies.
Any mediation, arbitration, venue selection, or other dispute resolution requirements applicable to a construction project will be governed by the executed project agreement and applicable law.
These website terms do not impose an automatic waiver of the right to seek relief in court.
21. Governing Law
These Terms and Conditions are governed by the laws of the State of Florida, without regard to conflict-of-law principles.
Any legal proceeding arising solely from these website terms will be subject to the jurisdiction of courts having lawful authority in Florida.
Project-specific jurisdiction and venue provisions, if any, will be established in the applicable written construction agreement.
22. Privacy and Data Protection
FIG Construction Services respects the privacy of website visitors and customers.
Personal information submitted through our website may be used to respond to inquiries, schedule consultations, prepare proposals, administer customer relationships, and provide requested services.
Information may be processed using authorized business technology providers, including customer relationship management and scheduling platforms.
Additional information regarding data collection, communications, cookies, retention, and privacy rights is provided in our Privacy Policy.
Privacy Policy: https://figconstructionservices.com/privacy-policy
23. Severability
If any provision of these Terms and Conditions is determined to be invalid or unenforceable, the remaining provisions will continue in effect to the extent permitted by law.
24. Entire Agreement
These Terms and Conditions and the Privacy Policy govern website access and related online interactions.
Any executed construction agreement, together with its incorporated documents and authorized amendments, governs the applicable construction project.
These website terms do not supersede or replace the terms of an executed construction agreement.
25. Contact Information
For questions regarding these Terms and Conditions, construction services, consultations, or customer communications, please contact:
FIG Construction Services LLC
Florida Certified General Contractor
License: CGC1540893
Phone: (407) 205-8901
Website: https://figconstructionservices.com
Service Areas: Central Florida, Tampa Bay, and other Florida locations based on project scope and availability.
Building with Purpose. Delivering with Integrity.